Follow the procedures at PGI 236.203 for handling the Government estimate of construction costs.

[71 FR 9273, Feb. 23, 2006]

Additional price ranges are—

(i) Between $10,000,000 and $25,000,000;

(ii) Between $25,000,000 and $100,000,000;

(iii) Between $100,000,000 and $250,000,000;

(iv) Between $250,000,000 and $500,000,000; and

(v) Over $500,000,000.

[61 FR 7749, Feb. 29, 1996]

See 211.503 for instructions on use of liquidated damages.

[56 FR 36421, July 31, 1991, as amended at 66 FR 49861, Oct. 1, 2001]

See PGI 236.211 for instructions on reporting data for definitization of requests for equitable adjustment.

[88 FR 73237, Oct. 25, 2023]

If it appears that sufficient funds may not be available for all the desired construction features, consider using a bid schedule with additive or deductive items in accordance with PGI 236.213.

[71 FR 9273, Feb. 23, 2006]

For contracts in connection with a military construction project or military family housing project, see the prohibition at 216.301-3.

[81 FR 65564, Sept. 23, 2016]

(a) 10 U.S.C. 2858 requires agency head approval to expedite the completion date of a contract funded by a Military Construction Appropriations Act, if additional costs are involved. This approval authority may not be redelegated. The approval authority must—

(1) Certify that the additional expenditures are necessary to protect the National interest; and

(2) Establish a reasonable completion date for the project.

(b) The contracting officer may approve an expedited completion date if no additional costs are involved.

Annual military construction appropriations acts restrict the use of cost-plus-fixed-fee contracts (see 216.306(c)). See also 216.301-3 regarding the prohibition on the use of certain cost-reimbursement contracts in connection with a military construction project or military family housing project.

[81 FR 65565, Sept. 23, 2016]

(a) Prequalification procedures may be used when necessary to ensure timely and efficient performance of critical construction projects. Prequalification—

(1) Results in a list of sources determined to be qualified to perform a specific construction contract; and

(2) Limits offerors to those with proven competence to perform in the required manner.

(b) The head of the contracting activity must—

(1) Authorize the use of prequalification by determining, in writing, that a construction project is of an urgency or complexity that requires prequalification; and

(2) Approve the prequalification procedures.

(c) For small businesses, the prequalification procedures must require the qualifying authority to—

(1) Request a preliminary recommendation from the appropriate Small Business Administration regional office, if the qualifying authority believes a small business is not responsible;

(2) Permit the small business to submit a bid or proposal if the preliminary recommendation is that the small business is responsible; and

(3) Follow the procedures in FAR 19.6, if the small business is in line for award and is found nonresponsible.

(a) In accordance with section 112 of the Military Construction and Veterans Affairs and Related Agencies Appropriations Act, 2015 (Division I of Pub. L. 113-235) and the same provision in subsequent military construction appropriations acts, military construction contracts funded with military construction appropriations, that are estimated to exceed $1,000,000 and are to be performed in the United States outlying areas in the Pacific and on Kwajalein Atoll, or in countries bordering the Arabian Gulf (i.e., Iran, Oman, United Arab Emirates, Saudi Arabia, Qatar, Bahrain, Kuwait, and Iraq), shall be awarded only to United States firms, unless—

(1) The lowest responsive and responsible offer of a United States firm exceeds the lowest responsive and responsible offer of a foreign firm by more than 20 percent; or

(2) The contract is for military construction on Kwajalein Atoll and the lowest responsive and responsible offer is submitted by a Marshallese firm.

(b) See PGI 236.273(b) for guidance on technical working agreements with foreign governments.

[56 FR 36421, July 31, 1991, as amended at 62 FR 2856, Jan. 17, 1997; 62 FR 34127, June 24, 1997; 63 FR 11538, Mar. 9, 1998; 66 FR 49861, Oct. 1, 2001; 70 FR 35545, June 21, 2005. Redesignated and amended at 71 FR 9273, Feb. 23, 2006; 79 FR 44316, July 31, 2014; 80 FR 15911, Mar. 26, 2015]

In accordance with section 108 of the Military Construction and Veterans Affairs Appropriations Act, 2009 ( Pub. L. 110-329, Division E) and the same provision in subsequent military construction appropriations acts), do not acquire, or allow a contractor to acquire, steel for any construction project or activity for which American steel producers, fabricators, or manufacturers have been denied the opportunity to compete for such acquisition of steel.

[74 FR 2418, Jan. 15, 2009, as amended at 80 FR 15911, Mar. 26, 2015]

See Subpart 237.75 for policy relating to facilities projects.

[74 FR 37646, July 29, 2009]